First, this decoration contract is provided to everyone for reference only.
Second, the contract is only a contract, do not place too high expectations on it, the most critical thing is to choose a good team.
Family room decoration decoration construction contract
The Employer (hereinafter referred to as Party A): ________________________________________
ID number: _________________________________________________
Residence: ____________________________________________________
contact number: _________________________________________________
phone number: __________________________________________________
Contractor (hereinafter referred to as Party B): ________________________________________
ID number: _________________________________________________
Residence: ____________________________________________________
contact number: _________________________________________________
phone number: __________________________________________________
In accordance with the "People's Republic of China Contract Law" and other relevant laws and regulations, combined with the characteristics of Beijing's family room decoration, Party A and Party B, on the basis of equality, voluntariness, and consensus, will contract Party B to contract Party A's family room decoration. Relevant matters of the renovation project (hereinafter referred to as the project) have reached the following agreement:
I. Project Overview
1. Project location:
2. Project decoration area:
3. Project type:
4. Project contents and practices: See the project content and budget (Annex 1), decoration process requirements (Annex 3).
5. Project contracting, adopting Party B's contracting work, including construction tools and equipment, and Party A's provision of construction materials.
6. Construction deadline
Start date:
Completion date:
7. Contract price:
The contract construction cost is (RMB): yuan
Amount of capital:
The quoting quotation is based on the reference price of the Beijing Home Decoration Project, based on the rules of economic operation at regular times, and both parties agree in the contract based on the principle of high quality and preferential price. The quotation of the contract shall be compiled with the material quality standards and the system of safety and security as the basis for the project price.
Second, project supervision
If this project implements project supervision, Party A shall sign the "project supervision contract" with the project supervision company that has been approved by the construction administrative department, and notify Party B of the name, unit, contact information, and responsibilities of the project supervision engineer of the supervision engineer.
Third, the construction drawings
The construction drawings are entrusted by Party A to Party B to design and provide construction drawings in triplicate. Party A shall hold one copy and Party B shall hold two copies.
Fourth, the work of Party A
1. To create conditions for Party B's admission construction three days before the start of construction, the principle of construction will not be affected.
2. Provide free water, power and winter heating during construction.
3. Responsible for handling the start-up procedures of the house property department and related expenses that should be paid by the owner.
4. Comply with the rules and regulations of the property management department.
5. Responsible for coordinating the relationship between the on-site construction team and the neighborhood.
6. Participate in the supervision of project quality construction progress, participate in acceptance of engineering materials, inspection and acceptance of concealed projects, and completion acceptance.
V. Work of Party B
1. Strictly implement the safety construction operation rules, fire prevention regulations, construction specifications and quality standards during construction, and complete the contract project on schedule.
2. It shall not disturb people or pollute the environment. No decoration activities such as knocking, chiselling, creating, drilling and other noises shall be carried out from 12:00 to 14:00, 18:00 to 8:00 daily.
(3) Party B shall be responsible for repairs and damages as a result of the construction of the decoration, which results in blockage, leakage, water stoppage, and power outage of the adjacent residents' houses.
4. Responsible for the protection of finished furniture, equipment, and furnishings preserved in the house.
5. Ensure that the indoor and sewer pipes are clean and the bathroom is clean.
6. Ensure the cleanliness of the construction site, clean the construction site after daily completion, and remove the garbage to the designated place of the property.
7. Provide Party A with written information on various standards, specifications, calculations, reference prices, etc. involved in the signing and implementation of this contract.
Sixth, engineering changes
During the construction period, if there is a need to change the contractual project contents, both parties shall agree. The parties to the contract jointly sign a written change agreement and adjust the related engineering fees and periodicities. The engineering change order is used as the basis for the completion settlement and the extension of the construction period.
Seven, material supply
1. Party B shall provide Party A with a list of materials to be purchased five days in advance. Party A shall promptly purchase materials for use by the construction team within four days. Both parties shall bear their own responsibility for delaying the construction period and economic losses.
2. Without the consent of Party A, Party B may not purchase materials on its own. If it has been purchased, Party A has the right to refuse to use it and may refuse to pay for the material.
3. Party B shall purchase materials at the building material supply point designated by Party A and issue an official invoice.
4. Party B shall accept the quality of the building materials purchased by Party A. It is found that quality problems should be promptly raised to Party A and have the right to refuse to use it. If Party A insists on using it, Party B shall request Party B in writing and bear the loss caused by the quality of the material.
5. Party B shall help Party A to receive the goods and check the accuracy of the quantity and accessories.
6. Party B should do a good job of keeping the materials, and it is forbidden for people to enter the site.
7. Without the permission of Party A, Party B shall not carry any building materials to go out. If such phenomena are found, the price of materials shall be doubled from the labor cost.
8. Party A materials shall be sent downstairs to the location of the project. Any construction personnel of Party B shall be carried unconditionally.
VIII. Delay in construction period
1. The delay in the date of completion due to the following reasons shall be confirmed by Party A. The duration of the project shall be postponed: the quantity of the project changes; it is force majeure; and Party A agrees that the duration of the project will be postponed.
2. Because the responsibility of Party B cannot be completed on schedule, the construction period will not be postponed. The cost of rework due to the cause of Party B's problems will be borne by Party B. The construction period will not be postponed.
3. Due to Party B's delay in the construction period, for every one day's delay, Party A shall compensate Party A for losses in accordance with 2% of the total project payment.
Nine, quality standards
1. The interior pollution control of interior decoration shall be strictly implemented in accordance with the Standards for Indoor Environmental Pollution Control of Civil Construction Projects (GB50325-2001).
2. The construction quality of this project shall be implemented according to "Beijing Quality Standard for Family Room Decoration Projects" (DBJ/T01-43-2000).
3. Both parties have disputes on project quality and indoor air quality when they are finished and accepted. They apply for a professional inspection unit that has been approved by the construction administrative department of Beijing Municipality and the quality and technical supervision department to certify the project quality and indoor air quality. The costs associated with the certification process are borne by the responsible party.
X. Project acceptance and warranty
1. Joint acceptance of project quality at the following stages during the construction process:
(1) Material acceptance;
(2) Hidden project acceptance;
(3) Completion acceptance.
2. After the completion of the project, Party B informs Party A of acceptance.
3. Before the two parties complete the acceptance check, Party B shall be responsible for the protection of the complete safety of the finished product and the project site.
4. From the date of acceptance of the completion of the project, the warranty period for the interior decoration works under normal conditions of use shall be two years. The warranty period for the leakage protection of kitchens and toilets with waterproof requirements shall be five years.
XI. Construction payment methods
1. After the signing of the contract takes effect, Party A will pay the construction fee to Party B according to the contract in the contract:
Payment times Payment time Payment rate according to the project payment
The first worker, material approach
The second time the progress of the project is more than half
The third time passed the acceptance
One year after completion of the fourth acceptance
2. More than half of the progress of the project means: the end of carpentry production; the end of the wall, floor tile and ceiling; the leveling of the wall; the completion of the hydropower reform.
3. The project payment shall be settled according to the actual amount of the project.
4. After the construction funds are fully settled, Party B issues an official invoice to Party A as the main project certificate.
XII. Liability for breach of contract
1. If a party fails to perform the contractual obligation to the other party in accordance with the contract, it shall bear the liability for compensation; if the party is punished for violating the relevant laws and regulations, the ultimate responsibility shall be borne by the responsible party.
2. If one party cannot continue to perform the contract, it shall promptly notify the other party and the responsible party shall bear the losses caused by the cancellation of the contract.
3. Party A did not pay for the third or fourth construction projects without justified reasons according to the contractual time limit, and paid Party B's liquidated damages of 2% of the contract's construction cost on each delay day.
4. As Party B's responsibility leads to unqualified project quality and indoor air quality, Party B shall perform rework repairs, comprehensive treatment and compensation according to the following terms:
(1) Party B must perform thorough rework to repair the site where the quality of the project is not qualified. The delayed payment of the project due to rework is regarded as the delay of the same project. On each delay day, Party B shall pay Party B the liquidated damages of 2% of the construction cost of the contract.
(2) For unqualified indoor air quality, Party B must carry out comprehensive management. Due to governance, delayed delivery of the project is regarded as a delay in the same project. For each delay of one day, Party B shall pay Party B the liquidated damages of 2% of the contract's construction cost.
(3) If the indoor air quality still fails to meet the standard, Party B shall return the full price of the project of Party A's contract.
XIII. Dispute Resolution
In case of disputes arising under this contract, both parties shall, when negotiating or applying to the consumer association for mediation resolution, consultation or mediation, resolve the matter to the people's court in the place where the project is located and invite the people's court to make a ruling.
XIV. Labor Management
1. Before the commencement of work, Party B shall provide Party A with a copy of the ID of all construction workers.
2. Without the permission of Party A, non-site construction personnel shall not spend the night on site.
3. Party A shall promptly handle the community access documents for Party B and pay related fees.
4. Party B shall have all documents for temporary stay in Beijing. The relevant losses caused by incomplete documents shall be borne by Party B itself.
5. Party B designates the site responsible person for the site and the replacement person in charge.
6. Party B shall not arbitrarily change construction workers without the consent of Party A.
7. Without the consent of Party A, Party B shall not suspend or complete the work under any circumstances.
15. Construction Machinery
1. Party B brings the necessary tools for construction and guarantees the safety and good use of the tools. Party B shall bear the cost of tool maintenance.
2. The consumables (such as drills, saw blades, etc.) generated by the tool shall be borne by both parties A and B by 50%.
16. Site Management on Site
1. It is forbidden to use open flame at the scene.
2. No smoking on site.
3. Paint materials must be placed separately from other materials.
17. Supplementary Provisions
1. This contract is made in two copies and will become effective upon signature by both parties.
2. The project shall not be subcontracted after signing this contract.
3. Both parties may make changes or supplements to this contract in written form. However, if the change or supplement unreasonably reduces or exempts the liability that Party B should bear in this contract, it shall still be subject to this contract.
4. If the performance of the contract or the cause of the loss is affected due to the fact that they cannot be imputable and the reasons of both parties, both parties should settle the matter in accordance with the principle of fairness.
5. The contract will be automatically terminated when it is completed.
18. Other matters
1. Party B shall check the material quality and construction quality of the construction site; the materials provided by Party A shall be used only after Party B's inspection.
2. Party B shall inform Party A 48 hours in advance of the completion of the following key processes for acceptance. After acceptance, Party B may proceed with the next process:
A, material approach
B. Hidden project
C. Waterway and Circuit Reconstruction
D. Waterproofing and water-blocking experiments
E, joinery substrate engineering
F, panel, wood line, solid wood cover
G, primer, topcoat
H, wall, top surface treatment
I. Suspended ceiling keel panel
J, all parts of the plate
K, Mid-term acceptance of the project
L. Overall acceptance of the project.
The above sub-projects have not been accepted by Party A, and Party B has carried out the construction of the next procedure without authorization. Therefore, Party B shall be responsible for the loss of work materials.
3. The main materials and quantity provided by Party B (including various plates, keels, water and electricity materials, paint, cement, plastics, paints, putty powder, plaster lines, etc.) must be the same as the materials listed on the list of materials attached to this contract. Consistent, and notify Party A to verify it when entering the market. Party B shall present to party A relevant proofs of the purchase of materials (invoices or shopping papers or proof of company's unified supply), environmental protection certificates, warranty certificates, sources of materials, etc. Party A shall have the right to verify the authenticity of the materials with the manufacturer or distributor. If it is found that the materials provided by Party B are counterfeit products or products that do not comply with national, local, and relevant ministry standards and regulations, Party B must promptly replace the products agreed in the contract or other qualified products of the same price recognized by Party A and follow the contract. The double price of the market price of the agreed materials will compensate Party A; if Party B can prove that the legally recognized evidence fully proves that it is due to the responsibility of the supplier, Party A can appropriately reduce the amount of compensation required according to the specific circumstances, and Party B can supply the materials. The company pursues corresponding responsibilities. For the part that has been used for construction, Party A has the right to request Party B to dismantle and redo the work. The expenses incurred by Party B shall be borne by Party B.
4. Special trades such as electricians and plumbers are required to hold relevant certificates and undergo inspection before they can go on duty.
5. The project changes must have a written agreement, specify the number of changes and prices in detail and be signed by both sides of the A and B can be used as a basis for settlement.
6. Construction process standard implementation <GB50327-2001> Project acceptance standard implementation <GB50210-2001> Environmental protection standard implementation <GB50325-2001> The contractor who does not meet this standard shall bear compensation for non-compliance projects.
7. The decoration materials provided by Party A arrive at the scene, and Party B can only use it after passing the acceptance of quality and quantity. Once it is used, it shall be deemed as qualified. The resulting construction quality problems shall be the full responsibility of Party B. If Party B can prove after the fact that the quality problem is indeed caused by the unqualified material provided by Party A, and the quality problem cannot be discovered through conventional means such as observation, hand touch, and ruler measurements, the parties A and B shall bear 50 %Responsibility.
8. Party B is obliged to properly maintain the materials provided by Party A. Party B shall be responsible for compensation if any damage or loss occurs. Party B must clean up and collect the garbage generated during the renovation process and place it in the designated place of the property department.
9. During the construction process, Party B shall abide by the construction safety operation regulations, be responsible for the safety management at the construction site, take the necessary safety protection and fire prevention measures, ensure the safety of personnel, and avoid the loss of Party A's houses and other properties. Party B shall not occupy public space during construction and shall not damage the facilities in public areas. All civil and criminal liabilities incurred by Party B's construction workers during the construction and maintenance period shall be borne by Party B.
10. In the project, if Party A wishes to increase the project or if it is a design calculation failure or intentional missing item, the Party shall increase the project price by reference to the single quotation of the contract.
11. During the construction period, Party A believes that the construction personnel of Party B are not qualified for the decoration work due to the level of workmanship, work attitude, and character, etc., and have the right to require Party B to replace the construction personnel.
12. During the warranty period, the owner informs the construction party that it needs repairs. The construction party must arrive at the site within 24 hours. If the repair is caused due to the construction quality of Party B or the quality of the materials provided, it cannot be submitted within 48 hours after Party A writes the repairs. , Party A can solve the problem on its own, and all expenses incurred by Party A shall be borne by Party B. If, during the warranty period, an accident involving endangerment of personal safety or other property safety involving water, electricity, gas, etc., arises because of engineering quality problems, Party A may first deal with it and Party B shall pay Party B for all reasonable expenses it has incurred. During the warranty period, Party B shall bear the responsibility of replacement if it is found to have serious deformation or repair that will affect the overall appearance.
Entrance decoration children's room decoration decoration interior decoration door price home decoration paint bathroom door bathroom ceiling material bathroom design bathroom waterproof price bathroom ceiling overall bathroom public bathroom bathroom waterproof bathroom floor tile
Home Decoration,Tablewares And Kitchenwares,Mugs AND Cups Co., Ltd. , http://www.nsdecoration.com